.....................................................................................................................................

Art. VII. Should the Contractor be delayed in the prosecution or completion of the work by the act, neglect or default of the Owner , of the Architect , or of any other contractor employed by the Owner upon the work, or by any damage caused by fire, lightning, earthquake, cyclone or other casualty for which the Contractor ..................... not responsible, or by strikes or lockouts caused by acts of employes, then the time herein fixed for the completion of the work shall be extended for a period equivalent to the time lost by reason of any or all the causes aforesaid, which extendi d period shall be determined and fixed by the Architect; but no such allowance shall be made unless a claim therefor is presented in writing to the Architect within forty-eight hours of the occurrence of such delay.

Art. VIII. The Owner agree to provide all labor and materials essential to the conduct of this work not included in this contract in such manner as not to delay its progress, and in the event of failure so to do, thereby causing loss to the Contractor , agree that........................will reimburse the Contractor for such loss; and the Contractor agree that if.........................shall delay the progress of the work so as to cause loss for which the Owner shall become liable, then........................shall reimburse the Owner for such loss.

Should the Owner and Contractor fail to agree as to the amount of loss comprehended in this Article, the determination of the amount shall be referred to arbitration as provided in Article XII of this contract subject to additions and deductions as hereinbefore provided, and that such sum shall be paid by the Owner to the Contractor , in current funds, and only upon certificates of the Architect , as follows:

Art. IX. It is hereby mutually agreed between the parties hereto that the sum to be paid by the Owner to the Contractor for said work and materials shall be.....................

...............................................................................................................................................

...............................................................................................................................................

The final payment shall be made within...................................................................................days after the completion of the work included in this contract, and all payments shall be due when certificates for the same are issued.

If at any time there shall be evidence of any lien or claim for which, if established, the Owner of the said premises might become liable, and which is chargeable to the Contractor ,the Owner shall have the right to retain out of any payment then due or thereafter to become due an amount sufficient to completely indemnify...............

against such lien or claim. Should there prove to be any such claim after all payments are made, the Contractor shall refund to the Owner all moneys that the latter may be compelled to pay in discharging any lien on said premises made obligatory in consequence of the Contractor default.

Art. X. It is further mutually agreed between the parties hereto that no certifcate given or payment made under this contract, except the final certificate or final payment, shall be conclusive evidence of the performance of this contract, either wholly or in part, and that no payment shall be construed to be an acceptance of defective work or improper materials.

Art. XI. The Owner shall during the progress of the work maintain insurance on said work, in.........................................own name and in the name of the Contractor, against loss or damage by fire, lightning, earthquake, cyclone or other casualty. The policies to cover all work incorporated in the building, and all materials for the same in or about the premises, and shall he made payable to the parties hereto, as their interest may appear.

Art XII. In case the Owner and Contractor fail to agree in relation to matters of payment, allowance or loss referred to in Arts. III or VIII of this contract, or should either of them dissent from the decision of the Architect referred to in Art. VII of this contract, which dissent shall have been filed In writing with the Architect within ten days of the announcement of such decision, then the matter shall be referred to a Board of Arbitration consisting of......................................................................................................................................-

....................................................................................................................................in behalf of the Owner , and

.................................................................................,..................................................in behalf of the Contractor , these two to select a third. The decision of any two of this Board shall be final and binding on both parties hereto. In event of the death or inability to serve of the party named in behalf of the Owner , then the Owner shall select a person in his place; in event of the death or inability to serve of the party named in behalf of the Contractor , then the Contractor shall select a person in his place; in event of the death or inability to serve of the third party, then the remaining arbitrators shall choose a person in his place. Each party hereto shall pay one-half of the expense of such reference.

Art. XIII. The said parties for themselves, their heirs, successors, executors, administrators and assigns, do hereby agree to the full performance of the covenants herein contained.

In Witness thereof, the parties to these presents have hereunto set their hands and seals, the day and year first above written.

In Presence of