books



previous page: The Law Of Contracts Vol5| by William Herbert Page
  
page up: Business Law Books
  
next page: A Treatise On The Construction Of The Statute Of Frauds | by Causten Browne

The Law Of Contracts Vol7| by William Herbert Page



Forms, Precedents And Suggestions For Drafting Contracts

TitleThe Law Of Contracts Vol7
AuthorWilliam Herbert Page
PublisherThe W. H. Anderson Company
Year1919
Copyright1919, The W. H. Anderson Company
AmazonCommercial Contracts: A Practical Guide to Deals, Contracts, Agreements and Promises
-Forms, Precedents And Suggestions For Drafting Contracts
Sec. 3762. General form of contract. Sec. 3763. Execution by agent. Sec. 3764. Execution by private corporation. Sec. 3765. ...
-Sec. 3762. General Form Of Contract
This contract, entered into this---------day of---------, A. D. 19 - , at---------, by and between A. B. of --------- in the County of --------- and State of -------party of the first part and C. D. o...
-Sec. 3763. Execution By Agent
In witness whereof the said A. B. by his agent X. Y. has hereunto set his hand the day and year first above written. A. B., By X. Y., as agent of A. B. For liability arising on various forms of sign...
-Sec. 3764. Execution By Private Corporation
In witness whereof the said X. Y. Company has caused its corporate name to be signed hereto by L. M., its president, and it has caused its corporate seal to be hereto affixed by its said president, an...
-Sec. 3765. Execution By Public Corporation
In witness whereof the said city of X. has caused its name to be signed hereto and its corporate seal to be affixed hereto by [insert title of duly authorized officer] on the day and year aforesaid. ...
-Sec. 3766. Condition - General Form
Provided, however, and this contract is upon this condition, that if [recite breach of condition] this contract shall be void and of no effect, and in such case [make provision for restitution or forf...
-Sec. 3767. Condition - Breach Of Covenant As Discharge At Election Of Party Not In Default
In case the said A..B. shall fail to perform his covenant hereinbefore set forth, whereby he agrees to [insert substance of specific covenant], the said C. D. may, at his election, declare such contra...
-Sec. 3768. Covenant For Liquidated Damages
Whereas, the breach of the foregoing covenant will cause a serious and substantial damage to the said A. B., and whereas, it would be difficult, and in most cases impossible, to prove the amount of su...
-Sec. 3709. Covenant Making Time Of The Essence Of The Contract
It is mutually agreed between the parties to this contract that time is of essence thereof; and that in case either party shall fail to perform the covenants on his part to be performed, at the time f...
-Sec. 3770. Consideration - Promise To Pay Debt Barred By Bankruptcy
This contract entered into this--------- day of ---------, 19 -, by and between A. B. of the City of ---------, State of ---------, party of the first part, and C. D. of the City of ---------, State...
-Sec. 3771. Special Classes Of Contracts - Adoption
This contract made this --------- day of --------, by and between A. B. of the City of---------, State of --------, party of the first part, and C. D. and E. F. [husband and wife] of the City of-----...
-Sec. 3772. Advertising Contract
This contract entered into on the --------- day of ---------, between the X. Y. Publishing Company of the City of --------- and State of ---------, and A. B. of the City of---------and State of -----...
-Sec. 3773. Agency - Power Of Attorney
Know all men by these presents: That I, A. B., of the --------- State of ---------, have made, constituted and appointed, and by these presents do make, constitute and appoint, C. D., of the --------...
-Sec. 3774. Annuity
This contract entered into on the --------- day of ---------, between A. B., of the City of---------, State of ---------, and C. D., of the City of ---------, State of --------, Witnesses: That wher...
-Sec. 3775. Apprenticeship
This contract made and concluded at---------,---------, this---------day of---------, A. D. 19-, by and between A. B. and C. D., his eon [or daughter] of the---------, ---------County,---------, and...
-Sec. 3776. Partnerships - Articles Of Co-Partnership
Articles of agreement made and concluded this --------- day of ---------, 19 - , by and between A. B. and C. D., both of---------, Witnesses: Article I. -That the parties hereto have agreed to and do...
-Sec. 3777. Article Permitting One Partner To Purchase Interest Of Other, On Dissolution: Price To Be Arbitrated
[lnsert in Articles of Co-partnership, above, at end of Article providing for division of assets, on dissolution.] Provided, however, that, on dissolution of said partnership, either partner shall ha...
-Sec. 3778. Article Requiring Partner To Purchase Or Sell, On Dissolution
[Insert in Articles of Co-partnership, above, at end of Article providing for division of assets, on dissolution.]. Provided, however, that, on dissolution of said partnership, either partner may mak...
-Sec. 3779. Article Providing For Public Sale Of Assets, On Dissolution
[Insert after Article providing for division of assets on dissolution.] If, upon dissolution or other termination of this partnership, the partners are unable to agree upon a division of the assets, ...
-Sec. 3780. Article Permitting Either Partner To Dissolve Partnership If Capital Becomes Impaired
[Insert in Articles of Co-partnership, above, immediately after Article providing for periodical accounts.] If it shall appear, at any annual [or, quarterly] account, that losses have been incurred w...
-Sec. 3781. Article Permitting Partner To Dispose Of His Interest. After
[Omit from Articles of Co-partnership, above, the prohibition against assignment, pledge or mortgage of the interest of either partner, and add the following to the same clause.] Either partner may a...
-Sec. 3782. Article Providing For Arbitration
If any controversy or difference shall arise between said partners, at any time during the continuance of said partnership, or thereafter and before final settlement, between the partners, regarding t...
-Sec. 3783. Agreement Of Dissolution; One Partner Purchasing Interest Of Other
This contract entered into at ---------, this --------- day of ---------, 19 -, by and between A. B. and C. D., Witnesses: That whereas under and by virtue of articles of co-partnership dated--------...
-Sec. 3784. Arbitration
This contract entered into this---------day of---------, at the City of---------, between A. B., of the City of---------, and C. D., of the City of---------, Witnesses: That, whereas, heretofore on o...
-Sec. 3785. Assignment Endorsed On Instrument - Short Form
---------, 19 -. For value received, I hereby sell, assign, transfer and set over the within [name of instrument] to C. D. A. B. For the nature and effect of assignment, see 89 2235 et seq. For the ...
-Sec. 3786. Assignment Of Account
Whereas E. F. is indebted to A. B. for the various articles set forth therein; and whereas the following is a true copy of such account with all credits thereon [insert itemized copy of account]; and ...
-Sec. 3787. Assignment Of Salary, Earned And Unearned
This contract made this---------day of ---------, 19 -, by and between A. B., of---------and C. D., of---------, Witnesses: That the said A. B. for a valuable consideration, the receipt of which is h...
-Sec. 3788. Assignment Of Land Contract
This contract made at ---------, this --------- day of ---------, 19 -, by and between A. B., of the -------- of ---------, County of --------- and State of ---------, party of the first part, and----...
-Sec. 3789. Assignment Of Literary Work Before Copyright
In consideration of the sum of --------- dollars ($---------), received to my full satisfaction of C. D., of ---------, I hereby sell, assign, transfer and set over unto the said C. D. the manuscript ...
-Sec. 3790. Assignment Of Copyright
In consideration of the sum of --------- dollars ($---------), received to my full satisfaction of C. D., of ---------, I hereby bargain, sell, assign, transfer and set over unto the said C. D., his e...
-Sec. 3791. Assignment Of Stock In Corporation
Know all men by these presents: That I, A. B., for value received, do hereby bargain, sell, assign and transfer to C. D., --------- shares of the stock of the --------- Company, standing in my name on...
-Sec. 3792. Assignment Of Stock In Corporation - Endorsed On Certificate
For value received, --------- hereby sell, assign and transfer unto ---------, the shares of capital stock represented by the within certificate, and do hereby irrevocably constitute and appoint------...
-Sec. 3793. Assignment Of Mortgage And Note
Know all men by these presents: That I, A. B., of ---------, for the consideration of --------- dollars ($---------), received to my full satisfaction of C. D., do hereby sell, assign, transfer and s...
-Sec. 3794. Assignment Of Mortgage - Endorsed On Instrument
-------, 19-. For value received, I hereby sell, assign and transfer unto --------- the within mortgages together with the note [or bond] secured thereby. See references under Sec. 3791. ...
-Sec. 3795. Assignment Of Oil And Gas Lease
Whereas, the Secretary of the Interior has heretofore approved an oil and gas mining lease, dated ---------, entered into by and between C. D., lessee, and A. B., lessor, conveying the following desc...
-Sec. 3796. Contract For Assignment Of Oil Lease
This agreement made and entered into this --------- day of ---------, by and between C. D., of ---------, first party, and E. F., of ---------, second party, witnesseth that: Whereas first party is t...
-Sec. 3797. Assignment Of Judgment
Know all men by these presents: That whereas I, A. B., of ---------, did on the --------- day of --------, 19-, by the consideration of [name of court] duly recover a judgment against E. F., of ------...
-Sec. 3798. Assignment Of Undivided Interest In Judgment To Attorney
This contract made this --------- day of ---------, 19-, by and between A. B., of ---------, and C. D., of ---------, Witnesses: Whereas A. B. has heretofore retained C. D. as his attorney at law to ...
-Sec. 3799. Assignment Of Claim For Unliquidated Damages
For value received, I hereby sell, assign and transfer unto C D., all my right, title and interest in any and all sums of money which may now be due and owing to me, by reason of the facts hereinafter...
-Sec. 3800. Auction - Contract Signed By Auctioneer
I hereby acknowledge that C. D. has been this day declared the hightest bidder and purchaser of [describe the property], at the sum of --------- dollars, and that he has paid into my hands the sum of ...
-Sec. 3801. Auction - Contract To Be Signed By Purchaser
I hereby acknowledge that I have this day purchased, at public auction, all that [describe property], for the sum of ---------dollars, and have paid into the hands of X. Y. (the auctioneer) the sum of...
-Sec. 3802. Bill Of Lading - Straight Bill
THE X. Y. RAILWAY COMPANY Straight Bill of Lading-Original-Not Negotiable. These Railroads do not accept for transportation Money, Gold, Silverware, Valuable Papers or Paintings nor any articles of ...
-Bill Of Lading - Straight Bill. Continued
Except where the loss, damage, or injury complained of is due to delay or damage while being loaded or unloaded, or damage in transit by carelessness or negligence, as conditions precedent to recovery...
-Sec. 3803. Bill Of Lading - Order Bill
THE X. Y. RAILWAY COMPANY Order Bill Of Lading - Original This Company does not accept for transportation Money, Gold, Silverware, Valuable Papers or Paintings nor any articles of extraordinary valu...
-Sec. 3804. Uniform Express Receipt
The Company will not pay over $50, in case of loss, or 50 cents per pound, actual weight, for any shipment in excess of 100 pounds, unless a greater value is declared and charges for such greater valu...
-Sec. 3805. Bond - General Form
Know all men by these presents: That we, A. B., of the City of ---------, State of---------, and E. F., of the City of---------, State of ---------, are held and firmly bound unto C. D., of the City ...
-Sec. 3806. Bond For Payment Of Money - General Form
Know all men by these presents: That I, A. B., of ---------, am held and firmly bound unto C. D., of ---------, or order (or, or bearer) in the sum of [here insert the penal sum, usually double the...
-Sec. 3807. Bond - Corporation, For Money Only - Secured By Mortgage-Option To Pay Before Maturity. United States Of America
State of ---------. No. --. $--------- - per cent. first mortgage gold bond. Loan of---------, secured by mortgage. The A. B. Company, of ---------, acknowledges itself indebted to the C. D. Trust...
-Sec. 3808. Coupon To Foregoing Bond
No. ---------. . $--------. On the---------day of ---------, the A. B. Company will pay to bearer at the office of the C. D. Company, in the City of---------,---------,---------dollars in gold coin, ...
-Sec. 3809. Trustee's Certificate To Foregoing Bond
The C. D. Trust Company hereby certifies that the within bond is one of the series and issues described in the mortgage therein mentioned. The C. D. Trust Company, By ---------. ...
-Sec. 3810. Bond To Secure Payment Of Annuity
Know all men by these presents: That we, A. B., of ---------, ---------, as principal, and X. Y., of---------,---------, as surety, are held and firmly bound unto C. D., of--------- in the sum of ---...
-Sec. 3811. Bond - Standard Form Of The American Institute Of
Know all men: That we,--------- [here insert the name and address or legal title of the Contractor], hereinafter called the Principal, and --------- [here insert the name and address or legal title of...
-Sec. 3812. Bond To Secure Performance Of Contract For Public Improvement
Know all men by these presents: That A. B., as principal, hereinafter referred to as the Contractor, and we, C. D. and E. F., as sureties and hereinafter referred to as the Surety, are held and firmly...
-Sec. 3813. Bond-Indemnity
Know all men by these presents: That we, A. B. of the City of ---------, State of ---------, and E. F., of the City of ---------, State of ---------, are held and firmly bound unto C. D., of the City...
-Sec. 3814. Bond To Retiring Partner, To Pay Debts Of Late Firm
Know all men by these presents: That we, A. B., of ---------, ---------, as principal, and E. F., of ---------,---------, and G. H., of--------,---------, as sureties, are held and firmly bound unto C...
-Sec. 3815. Bond To Protect Maker On Paying Lost Note
Know all men by these presents: That we, A. B. as principal and E. F. as surety, are held and firmly bound unto C. D. in the sum of --------- dollars ($---------), for which payment well and truly to...
-Sec. 3816. Bond To Protect Corporation Issuing New Certificate Of Stock In Lieu Of Lost Or Destroyed Certificate
Know all men by these presents: That we, A. B. as principal and E. F. as surety, are held and firmly bound unto the C. D. Company in the sum of -------- dollars ($---------), for which payment well a...
-Sec. 3817. Bond To Secure Payments By Purchaser Under Contract Of
Know all men by these presents: That we, A. B., of ---------, as principal, and E. F., of---------, as surety, are held and firmly bound unto C. D., of --------in the sum of --------- [here insert pen...
-Sec. 3818. Bond To Protect Purchaser Of Real Estate Against Incumbrances
Know all men by these presents: That we, A. B. as principal and E. F. as surety, are held and firmly bound unto C. D. in the sum of --------- dollars ($--------), for which payment well and truly to...
-Sec. 3819. Bond For Support Of Obligees
Know all men by these presents: That we, A. 8. as principal and E. F. and G. H. as sureties, are held and firmly bound unto C. D. and J. D. his wife, in the sum of --------- dollars ($---------), for ...
-Sec. 3820. Bond For Fidelity Of Employe - Bonding Company As Surety
Amount $---------. Annual Premium $---------. Whereas, C. D., of ---------, ---------, hereinafter called the employe, has been appointed to the office or position of A. B. in the service of-------...
-Sec. 3821. Standard Form Of The American Institute Of Architects
- Agreement between contractor and owner - Issued by the American Institute of Architects for use when a stipulated sum forms the basis of payment.1 This agreement made the---------day of---------, i...
-Sec. 3822. General Conditions Of Contract - Standard Form Of The. Index To The Articles Of The General Conditions
1. Definitions. 2. Documents. 3. Details and Instructions. 4. Copies Furnished. 5. Shop Drawings. 6. Drawings on the Work. 7. Ownership of Drawings. 8. Samples. 9. The Architect's Status. 10....
-Article 1. Principles And Definitions
(a) The Contract Documents consist of the Agreement, the General Conditions of the Contract, the Drawings and Specifications, including all modifications thereof incorporated in the documents before t...
-Article 2. Execution, Correlation And Intent Of Documents
The Contract Documents shall be signed in duplicate by the Owner and Contractor. In case of failure to sign the General Conditions, Drawings or Specifications the Architect shall identify them. The C...
-Article 3. Detail Drawings And Instructions
The Architect shall furnish, with reasonable promptness, additional instructions, by means of drawings or otherwise, necessary for the proper execution of the work. All such drawings and instructions ...
-Article 5. Shop Drawings
The Contractor shall submit, with such promptness as to cause no delay in his own work or in that of any other contractor, two copies of all shop or setting drawings and schedules required for the wor...
-Article 9. The Architect's Status
The Architect shall have general supervision and direction of the work. He is the agent of the owner only to the extent provided in the Contract Documents and when in special instances he is authorize...
-Article 10. The Architect's Decisions
The Architect shall, within a reasonable time, make decision's on all claims of the Owner or Contractor and on all other matters relating to the execution and progress of the work or the interpretatio...
-Article 11. Foreman, Supervision
The Contractor shall keep on his work, during its progress, a competent foreman and any necessary assistants, all satisfactory to the Architect. The foreman shall not be changed except with the consen...
-Article 12. Materials, Appliances, Employes
Unless otherwise stipulated, the Contractor shall provide and pay for all materials, labor, water, tools, equipment, light and power necessary for the execution of the work. Unless otherwise specifie...
-Article 13. Inspection Of Work
The Owner, the Architect and their representatives shall at all times have access to the work wherever it is in preparation or progress and the Contractor shall provide proper facilities for such acce...
-Article 14. Correction Of Work Before Final Payment
The Contractor shall promptly remove from the premises all materials condemned by the Architect as failing to conform to the Contract, whether incorporated in the work or not, and the Contractor shall...
-Article 19. Contractor's Liability Insurance
The Contractor shall maintain such insurance as will protect him from claims under workmen's compensation acts and from any other claims for damages for personal injury, including death, which may ari...
-Article 21. Fire Insurance
The Owner shall effect and maintain fire insurance upon the entire structure on which the work of this contract is to be done and upon all materials, in or adjacent thereto and intended for use thereo...
-Article 22. Guaranty Bonds
The Owner shall have the right to require the Contractor to furnish bond covering the faithful performance of the contract and the payment of all obligations arising thereunder, in such form as the Ow...
-Article 23. Cash Allowances
The Contractor shall include in the contract sum all allowances named in the Contract Documents and shall cause the work so covered to be done by such contractors and for such sums as the Architect ma...
-Article 24. Changes In The Work
The Owner, without invalidating the contract, may make changes by altering, adding to or deducting from the work the contract sum being adjusted accordingly. All such work shall be executed under the ...
-Article 26. Applications For Payments
The Contractor shall submit to the Architect an application for each payment and, if required, receipts or other vouchers showing his payments for materials and labor, including payments to-subcontrac...
-Article 27. Certificates And Payments
If the Contractor has made application as above, the Architect shall, not later than the date when each payment falls due, issue to the Contractor a certificate for such amount as he decides to be pro...
-Article 28. Payments Withheld
The Architect may withhold or, on account of subsequently discovered evidence, nullify the whole or a part of any certificate for payment to such extent as may be necessary to protect the Owner from l...
-Article 29. Liens
Neither the final payment nor any part of the retained percentage shall become due until the Contractor, if required, shall deliver to the Owner a complete release of all liens arising out of this con...
-Article 30. Permits And Regulations
The Contractor shall obtain and pay for all permits and licenses, but not permanent easements, and shall give all notices, pay all fees and comply with all laws, ordinances, rules and regulations bear...
-Article 32. Use Of Premises
The Contractor shall confine his apparatus, the storage of materials and the operations of his workmen to limits indicated by law, ordinances, permits or directions of the Architect and shall not unre...
-Article 34. Cutting, Patching And Digging
The Contractor shall do all cutting, fitting or patching of his work that may be required to make its several parts come together properly and fit it to receive or be received by work of other contrac...
-Article 35. Delays
If the Contractor be delayed in the completion of the work by any act or neglect of the Owner or the Architect, or of any employe of either, or by any other contractor employed by the Owner, or by cha...
-Article 37. Owner's Right To Terminate Contract
If the Contractor should be adjudged a bankrupt, or if he should make a general assignment for the benefit of his creditors, or if a receiver should be appointed on account of his insolvency, or if he...
-Article 38. Contractor's Right To Stop Work Or Terminate Contract
If the work should be stopped under an order of any court, or other public authority, for a period of three months, through no act or fault of the Contractor or of any one employed by him, or if the O...
-Article 39. Damages
If either party to this contract should suffer damage in any manner because of any wrongful act or neglect of the other party or of any one employed by him, then he shall be reimbursed by the other pa...
-Article 40. Mutual Responsibility Of Contractors
Should the Contractor cause damage to any other contractor on the work, the Contractor agrees, upon due notice, to settle with such contractor by agreement or arbitration, if he will so settle. If suc...
-Article 41. Separate Contracts
The Owner reserves the right to let other contracts in connection with this work. The Contractor shall afford other contractors reasonable opportunity for the introduction and storage of their materia...
-Article 43. Subcontracts
The Contractor shall, as soon as practicable after the signature of the contract, notify the Architect in writing of the names of subcontractors proposed for the principal parts of the work and for su...
-Article 44. Relations Of Contractor And Subcontractor
The Contractor agrees to bind every subcontractor and every subcontractor agrees to be bound, by the terms of the General Conditions, Drawings and Specifications, as far as applicable to his work, inc...
-Article 45. Arbitration
Subject to the provisions of Article 10, all questions in dispute under this contract shall be submitted to arbitration at the choice of either party to the dispute. The Contractor agrees to push the ...
-Article 44. Of The General Conditions Of The Contract
Relations of Contractor and Subcontractor. - The Contractor agrees to bind every Subcontractor and every Subcontractor agrees to be bound, by the terms of the General Conditions, Drawings and Specific...
-Sec. 3824. Building Contract
This contract made this --------- day of---------, 19-, by and between A. B., of the --------- State of ---------, party of the first part (hereinafter designated the Contractor -), and C. D., of the-...
-Sec. 3825. Building Contract
This contract entered into this --------- day of ---------, A. D. 19-, by and between A. B., of the---------, of---------, and State of---------, party of the first part, and C. D., of the---------of-...
-Sec. 3826. Building Contract
This contract made this --------- day of ---------, in the year ---------, by and between A. B., of ---------, party of the first part (hereinafter designated the Owner), and C. D., of ---------, par...
-Sec. 3827. Building Contract
This contract entered into on this --------- day of ---------, 19-, by and between ---------, of ---------, and hereinafter designated as First Party, and ---------, of ---------, hereinafter desig...
-Sec. 3828. Building Contract - Cost Plus - Issued By The American
This agreement made the---------day of---------, in the year nineteen hundred and ---------, by and between C. D., of the ---------, State of ---------, hereinafter called the Contractor, and A. B., o...
-Article 1. The Work to be Done and the Documents Forming the Contract
The Contractor agrees to provide all the labor and materials and to do all things necessary for the proper construction and completion of the work shown and described on Drawings bearing the title ---...
-Article a. Changes in the Work
The Owner, through the Architect, may from time to time, by written instructions or drawings issued to the Contractor, make changes in the above-named Drawings and Specifications, issue additional ins...
-Article 3. The Contractor's Duties And Status
The Contractor recognizes the relatione of trust and confidence established between him and the Owner by this Agreement. He covenants with the Owner to furnish his best skill and judgment and to co-op...
-Article 4. Fee For Services
In consideration of the performance of the contract, the Owner agrees to pay the Contractor, in current funds, as compensation for his services hereunder--------- ($---------), which shall be paid as ...
-Article 5. Costs To Be Reimbursed
The Owner agrees to reimburse the Contractor in current funds all costs necessarily incurred for the proper prosecution of the work and paid directly by the Contractor, such costs to include the follo...
-Article 6. Costs Not To Be Reimbursed
Reimbursement of expenses to the Contractor shall not include any of the following: (a) Salary of the Contractor, if an individual, or salary of any member of the Contractor, if a firm, or salary of...
-Article 7. Costs To Be Paid Direct By The Owner
In addition to items of cost noted in Article 5 for which the Owner reimburses the Contractor, the Owner shall pay all costs as follows: (a) Materials, supplies, equipment and transportation required...
-Article 8. Discounts, Rebates, Refunds
All discounts, rebates and refunds, and all returns from sale of surplus materials, equipment, etc., shall accrue to the Owner, and the Contractor shall make provisions so that they can be secured. ...
-Article 9. Contractor's Financial Responsibility
Any cost due to the negligence of the Contractor or anyone directly employed by him, either for the making good of defective work, disposal of material wrongly supplied, making good of damage to prope...
-Article 10. Separate Contracts
All portions of the work that the Contractor's organization has not been accustomed to perform or that the Owner may direct, shall be executed under separate contracts let by the Owner direct. In such...
-Article 11. Title To The Work
The title of all work completed and in course of construction and of all materials on account of which any payment has been made, and materials to be paid for under Article 7, shall be in the Owner. ...
-Article 12. Accounting, Inspection, Audit
The Contractor shall check all material and labor entering into the work and shall keep such full and detailed accounts as may be necessary to proper financial management under this Agreement and the ...
-Article 13. Applications For Payment
The Contractor shall, between the first and seventh of each month, deliver to the Architect a statement, sworn to if required, showing in detail and as completely as possible all moneys paid out by hi...
-Article 14. Certificates Of Payment
The Architect shall check the Contractor's statements of moneys due, called for in Article 13, and shall promptly issue certificates to the Owner for all such as he approves, which certificates shall ...
-Article 15. Disbursements
Should the Contractor neglect or refuse to pay, within five days after it falls due, any bill legitimately incurred by him hereunder (and for which he is to be reimbursed under Article 5), the Owner, ...
-Article 16. Termination Of Contract
[The provisions of this Article supersede all of Article 37 of the General Conditions of the Contract except the first sentence.] If the Owner should terminate the contract under the first sentence o...
-Sec. 3829. Standard Form Of Agreement Between Contractor And Subcontractor
Issued by the American Institute of Architects - For use in connection with the third edition of the standard form of agreement and general conditions of the contract.1 This agreement, made this ----...
-Sec. 3830. Building Contract - Waiver Of Priority Of Lien
The undersigned, A. B., Head-contractor -, C. D., Sub-contractor -, E. P., G. H. (etc.); and Material-men and laborers for the construction of a building upon a lot of ground owned by L. M. and descri...
-Sec. 3831. Building And Construction Contract - Street Improvement
Contract between the City of X., of the first part, and A. B., Contractor -, of the second part, for improving [insert name of street], from---------to--------by [insert nature of improvement], in pur...
-Specifications - General Provisions
(The headings of the various sections are simply for convenience in reference and are not to be considered a part of the specifications.) Definitions - Section 1. The term City wherever used in the...
-Specifications - General Provisions. Part 2
Assigning or subletting the whole or any portion of this contract shall not operate to release the Contractor or his bondsmen hereunder from any of the contract obligations. Sanitary Regulations - Se...
-Specifications - General Provisions. Part 3
Miscellaneous Work - Section 15. The work under this improvement shah be joined with existing improvements in a neat and workmanlike manner, and adjoining curbs, gutters and pavements shall be taken u...
-Specifications - General Provisions. Part 4
The City will- repair and maintain all openings made in the pavement subsequent to its acceptance by the City. Retainer - Section 21. The City will retain ten per cent of the entire cost of the work ...
-Items. Grading - Item 1
The grading shall include the proper shaping of sidewalks, the necessary slopes and the establishment of sub-grade for roadway, removing brush and trees and all necessary grubbing. Where the embankme...
-Under-Drainage - Item 2
Under this item, the Contractor shall provide the system of under-drainage provided for below. The location, depth, and width of the necessary trenches, and the size of the drain pipe to be used shal...
-Drains - Items 3, 4, 5, 6, 7 And 8
Under these items the Contractor shall provide the system of drains shown on the plans or ordered. Excavation. - All excavations shall be made in open trenches unless otherwise ordered. No tunneling ...
-T Branches - Items 9, 10, 11, And 12
Where directed, the drain pipe to be laid under Items 3 to 8 shall have a 6-inch T branch. Unused ends of branches shall be closed with a suitable cover well cemented in place. The special of which th...
-Slants - Items 13 And 14
Vitrified clay slants of size specified shall be inserted in brick or concrete drains where directed by the Engineer. They shall fulfill the requirements for vitrified pipe; they shall be neatly set ...
-Manholes - Item 15
Standard Manholes shall be four feet in inside diameter. The walls shall be built of 8-inch brick work and plastered on exterior surfaces with a one-half inch coat of mortar; interior joints shall be ...
-Drop Manholes - Item 16
Drop manholes will be built at such places as indicated on the plans and ' shall be constructed in strict accordance with the standard drawing for drop manholes, Acc. No. 6 on file in the office of th...
-Manholes Readjusted - Item 17
Where it is necessary to raise, lower or alter existing sewer or water manholes, such work shall be done as ordered. The price bid for each manhole shall include the necessary masonry and the resettin...
-Moving Water Stop Boxes - Item 18
Wherever in the opinion of the Engineer it is necessary to change the grade or shift the curb line, water stop boxes and stop cocks affected by such change shall be moved as directed. In the event of ...
-Inlets - Items 19, 20, 21, 22, And 23
Inlets, unless otherwise specified on the plans or ordered by the Engineer, shall be constructed in accordance with standard plans for the particular type called for, on file in the office of the Engi...
-Inlets Converted To Manholes - Item 24
At certain localities it may be necessary to change the location of existing inlets. At such places, if so ordered by the Engineer, the old inlet may be retained for the purpose of changing the direct...
-Inlets Readjusted - Item 25
Where it is necessary to raise, lower or alter existing inlets, such work shall be done as directed. The price bid shall include the necessary excavation, backfill, masonry and the resetting of castin...
-Traps - Item 26
Traps will be placed where called for on the plans, or where required by the Engineer. Traps will be of the Flap Valve type, conforming to the standard plans on file in the Engineer's office. They ...
-Castings - Item 27
When ordered the Contractor shall replace with new castings, manhole rims and covers, inlet gratings, frames and covers, or other castings as ordered. Such castings shall be in accordance with standar...
-Trench Excavation - Item 28
Excavation. - The excavation for masonry walls or other special structures as ordered shall be made in open trenches of the requisite width and depth. If deemed necessary the sides of the excavation s...
-Drainage Walls - Item 29
Drain walls shall be constructed as shown on the plans or ordered. The stones used shall be clean, hard limestone of proper size or other suitable material laid in horizontal courses and well bedded a...
-Concrete - Items 30, 31, And 32 Materials
The cement used shall be an established brand of Portland Cement, which shall meet all the requirements of the Standard Specifications for Portland Cement of the American Society for Testing Materials...
-Concrete Masonry - Item 33
The concrete to be used for masonry walls or other special structures as ordered shall be of the class designated and shall conform to the respective specifications therefor under the head of Concret...
-Reinforced Concrete - Item 34
Reinforced concrete will consist of Class 1 concrete, as specified under the head of Concrete, Item 30, with reinforcing steel, as shown on the plans or as specified. Proportioning and Mixing. - Pr...
-Reinforced Concrete - Item 34. Continued
Forms. - All forms for moulded concrete work shall be constructed of sufficient strength to obtain the necessary rigidity to prevent any motion of the forms while concrete is being placed, and must be...
-Rubble Concrete Masonry - Item 35
Rubble Concrete masonry will consist of Class III. Concrete, as specified under Concrete, Item 32, in which are firmly imbedded rubble stones to an extent of not over one-half ( 1/2) the volume of t...
-Brick Masonry - Item 36
Materials. - Common brick shall be clay or shale brick, sound, hard, thoroughly and evenly burned, of close texture, uniform in shape and size, and free from warps, cracks, or other defects. Dried bri...
-Granite Curbing - Items 37 And 38
Granite. - Granite curbing shall be of the best quality of granite, gneiss, or syenite, of uniform grain and texture, free from excess of mica, and showing an even distribution of constituent material...
-Curb Reset And Redressed - Item 39
On Gravel. - Under this item the Contractor shall reset to the proper fine and grade such portions of the old curbing as ordered. If necessary, the ends shall be redressed so as to make a joint not ex...
-Steel Protection Plate-Item 40
Steel protection plates for the curb will be five (5) inches deep and three-eighths (3/8) inches thick, with the top nosed off to a three-eighths (%) inch radius. They will be anchored to the walks by...
-Concrete Combined Curb And Gutter - Item 41
The concrete combined curb and gutter will be constructed after the sub-grade is approximately established. The trench will be excavated to a width of twenty-eight (28) inches, and to a depth of four...
-Steel Protected Concrete Combined Curb And Gutter - Item 42
This curb and gutter shall be constructed and paid for as provided under Concrete Combined Curb and Gutter, Item 41, except that some approved form of steel protection securely anchored to the body ...
-Concrete Curb - Item 43
Concrete curbs will be seven (7) inches thick by sixteen (16) inches deep, laid on a cinder bed six (6) inches thick and twelve (12) inches wide. The surface finish shall extend ten (10) inches down t...
-Steel Protected Concrete Curb - Item 44
This curb shall be constructed and paid for as provided for Concrete Curb Item 43. Steel protection will consist of a plate 3/8 x 4 with upper outside corner rounded to a 3/8 radius, with anchors...
-Integral Concrete Curb - Item 45
Integral concrete curb shall be constructed as shown on contract drawings. The concrete for integral curbs shall be of the same materials and proportions as that required for Concrete Pavement Item 61...
-Concrete Headers - Item 46
Concrete headers will be used to retain the paving at such intersections as the Engineer directs. Such headers will consist of Class 1 concrete, and will be ---------inches wide and---------inches dee...
-Flagging Reset And Redressed - Item 47
Under this item the Contractor shall reset such of the old cross-walks or gutter flagging as ordered. The stone shall be redressed to make one-half-inch joints and to remove badly rounded edges. The w...
-Broken And Crushed Stone - Item 48
Broken or crushed stone shall consist of fragments of clean, sound, hard limestone or equally good stone of the sizes ordered. The price bid per cubic yard shall be for the material in place. Where th...
-Cement Walks - Item 49
The cinder foundation for sidewalks shall be eight (8) inches in thickness. On this foundation shall be laid a three (3) inch layer of concrete of Class II. The wearing surface shall consist of a one ...
-Street Signs - Item 50
Street signs shall be furnished and installed at such intersections as the Engineer designates. Street signs shall conform to [insert reference to specifications, etc.], on file in the office of the C...
-Galvanized Iron Fence - Item 51
Calvanized Iron Fence will be installed on retaining walls where ordered by the Engineer. The fence shall be --------- inches high, with round pickets -------inches in diameter, bowed on top and space...
-Galvanized Hand Railing - Item 52
The galvanized iron hand rail will be built substantially in accordance with [insert reference to specifications, etc.], ...
-Extra Binder - Item 53
This item will constitute such asphaltic binder as may be required for filling pot holes or depressions in old pavement. The asphaltic binder must comply in all respects to the specifications for sam...
-Asphalt Pavement - Item 54
Excepting where the estimated amount of asphalt paving to be done is less than 100 square yards, each bidder must submit with his bid a letter stating the commercial names (if any) and the proportion,...
-Asphalt Pavement - Item 54. Continued
(A) It shall be thoroughly homogeneous and the various bituminous ingredients contained in it shall be in a state of complete solution. It shall not be oily to the touch. (B) It shall have a penetrat...
-Surface Mixture
Preparation. - The wearing surface shall be composed of sand filler and asphalt cement of the character elsewhere herein specified and mixed in the proper and definite proportions. When more than one ...
-Payment
Payment. - The price bid per square yard for asphalt pavement will include furnishing of all labor and material necessary to complete, as herein specified, the asphalt pavement above the concrete foun...
-Maintenance
Condition at Expiration of Guarantee. - In addition to the proper maintenance of the pavement during the period of guarantee the Contractor shall, at his own expense, just before the expiration of the...
-Asphaltic Concrete Pavement - Item 55
General Description. - Asphaltic concrete pavement may be laid with the ordinary foundation of concrete as specified for Asphalt Pavement or may be laid as a surfacing on top of existing granite, bric...
-Materials
Asphalts. - The Refined Asphalts, Fluxes, and Asphalt Cement used, must comply in all respects with the requirements specified for these materials under Asphalt Pavement Item 54. Stone. - The stone s...
-Bithulithic Pavement - Item 56
Subgrade. - The subgrade for Bitulithic Pavement will be --------- (---------) inches below and parallel to the finished grade of the roadway. On the sub-grade, prepared as specified under Grading Ite...
-Bowlder Pavement - Item 57
Foundation. - The depth of subgrade for Bowlder streets shall be sixteen (16) inches below the finished surface of the roadway. Upon the prepared subgrade, the entire surface of the roadway between t...
-Bowlder Repaving - Item 58
Under this item the Contractor shall replace, as directed, all bowlder pavements disturbed in prosecuting the work or the repaving of which is deemed . advisable to make the adjoining bowlder pavement...
-Brick Pavement - Item 59
The bidder shall state in his bid the kind of brick he proposes to use. Before beginning work the successful bidder must submit to the City a written statement from the paving brick manufacturer givin...
-Brick Pavement - Item 59. Continued
Sand-Cement Bed. - Upon the concrete foundation shall be spread a layer of mortar one inch in thickness and made of one part of Portland cement, and three parts of sand. Only sufficient water shall be...
-Monolithic Construction
Subgrade. - The subgrade shall be--------- (---------) inches below and parallel to the finished roadway surface. This shall be lightly sprinkled with water before placing the concrete. Placing and F...
-Brick Repaving - Item 60
Under this item the Contractor shall replace as directed, all brick pavements disturbed in prosecuting the work or the repaving of which is deemed advisable to make the adjoining brick pavement confor...
-Concrete Pavement - Item 61
General. - Concrete pavement shall consist of one-course work with or without a finished and blocked surface, and with or without reinforcement. The depth will usually be seven (7) inches or six (6) i...
-Concrete Pavement - Item 61. Continued
Reinforcing metal shall be placed between base and wearing course and shall not be less than two (2) inches from the finished surface of the pavement and otherwise shall be placed as shown on the draw...
-Durax Pavement - Item 62
The quality of the granite shall be equal in all respects to that required for Granite Pavement. Before the award of the contract the successful bidder shall notify the Engineer where he proposes to ...
-Granite Pavement - Item 63
Granite. - The granite blocks shall be of medium grained granite, showing an even distribution of its constituent materials. It shall be of uniform quality and texture, without seams or discolorations...
-Granite Pavement - Item 63. Continued
The remaining depth of the joints will then be filled, flush full, with additional pebbles, as above specified. The pebbles must be gotten into the joints with the smallest possible amount of sweeping...
-Special Granite Pavement (For Steep Grades) - Item 64
The requirements as to quality and samples to be submitted shall be the same as specified for granite pavement. Dimensions and Dressing. - The sizes of the blocks shall be as follows: five (5) to sev...
-Granite Repaving - Item 65
Under this item the Contractor shall replace, as directed, all granite pavements disturbed in prosecuting the work or the repaving of which is deemed advisable to make the adjoining granite pavement c...
-Granite Pavement With Old Blocks Redressed - Item 66
The existing blocks on the street to be improved shall be recut and redressed in such mauner as to form one or more blocks of smaller size. The dimensions of the new blocks, excepting as noted below, ...
-Macadam Pavement (Waterbound)-Item 68
Subgrade. - The subgrade, prepared as specified under Grading, Item 1, shall be uniformly twelve (12) inches below the finished grade of the roadway. First Course. - Upon the prepared subgrade, bet...
-Resurfacing, Finishing, Rolling And Oiling Roadway - Item 69
General. - This work will be done in connection with the resurfacing of existing water-bound macadam roadways. The resurfacing shall be done in general accordance with the specifications for water-bou...
-Bituminous Macadam Pavement - Item 70
Stone. - The stone to be used for macadam shall be clean, sound, hard limestone or other stone deemed equally acceptable, broken or crushed, to the sizes specified. All rolling shall be done as direc...
-Wood Block Pavement- Item 72
General. - Each proposal must be accompanied by a letter from one or more wood block manufacturers, each letter giving the location and capacity of his plant or plants and stating that.the said manufa...
-Wood Block Pavement- Item 72. Part 2
The specific gravity of the fraction between 315 degrees C. and 355 degrees C. shall not be less than 1.09 at 38/15.5 C. 6. The oil shall yield not more than 2% of coke residue. Oil B Co...
-Wood Block Pavement- Item 72. Part 3
Sand-Cement (Mortar) Bed. - Upon the concrete foundation shall be spread a layer of mortar 3/4 inch in thickness and made of one part of Portland Cement and three parts of sand. Only sufficient water ...
-Wood Block Repaving-Item 73
Under this item the Contractor shall replace as directed ail wood block pavement disturbed in prosecuting the work or the repaying of which is deemed advisable to make the adjoining wood block pavemen...
-Water Mains And Appurtenances - Items 79 To 88, Inclusive
Items 79 to 88, inclusive, cover the furnishing, hauling and laying complete of water pipe and all appurtenances thereto. All work and material under these items shall be in accordance with the genera...
-Readjusting Valve Boxes - Item 89
Where it is necessary to raise, lower or readjust water valve boxes, the Contractor will excavate to a'depth of 8 inches below the new level of the lower flange of the box, and to a width of 9 inches ...
-Lowering Water Main - Item 90
Under this item, the existing water main shall, if necessary, be lowered to such depth that the top of the pipe shall be three and one-half (3%) feet below the surface of the proposed roadway. The wo...
-Lowering Service Branches - Item 91
Under this item, the existing service branches will be lowered to a depth of approximately 3 1/2 feet below the surface of the proposed roadway, from the main to the property line. The price bid shal...
-Removing Existing Water Mains - Item 92
The price bid per lineal foot for removing existing water mains, where new and larger mains' are laid to replace them, shall be in full compensation for any additional excavation, removing from trench...
-Connecting Service Branches - Item 93
The price bid for connecting service branches shall be in full compensation for the removal from existing main and connecting with ferrule in new main, including the making of joints and the furnishin...
-Concrete Class 1 - Item 94, And Brick Masonry - Item 95
These relate to concrete and brick masonry constructed in connection with the installation of the water distribution system. All work and material shall correspond to the requirements of Items 30 and ...
-Brick Valve Chambers Complete - Item 96
Brick valve chambers shall be built in accordance with standard plans on file in the office of the Superintendent of Distribution of the City Water Works. Brick work shall conform to the requirements ...
-Sec. 3832. Contract For Sidewalk Improvement - Public Corporation
Contract between the City of---------, of the first part, and A. B., Contractor -, of the second part, for constructing sidewalks and appurtenances in---------, Sidewalk District No.---------, for th...
-Sec. 3833. Contract For Sewer - Public Corporation
Contract between the City of---------, of the first part, and A. B., Contractor -, of the second part, for making the sewerage improvement in---------. This agreement, made and entered into this ----...
-Sec. 3834. Composition With Creditors - General Form
We, the undersigned, being respectively creditors of A. B., of ---------, in the amounts set opposite our respective names below, do hereby severally agree, in consideration of this composition and of...
-Sec. 3835. Agreement Permitting Debtor To Conduct Business Under
This agreement made at---------, this --------- day of ---------, 19-, by and between the creditors of C. D., whose names are subscribed hereto, parties of the first part, and C. D., of---------, part...
-Sec. 3836. Agreement Permitting Creditor's Committee To Wind Up
This contract made this --------- day of ---------, 19-, between the X. Y. Company, a corporation organized under the laws of the State of ---------, with its principal office and place of business i...
-Agreement Permitting Creditor's Committee To Wind Up. Part 2
(i) To employ and compensate counsel, auditors and all necessary assistants for services rendered in and about the matters mentioned in this agreement, including the preparation hereof, and to incur a...
-Agreement Permitting Creditor's Committee To Wind Up. Part 3
10. Nothing in this agreement contained shall prevent any Creditor of the Company or any member of the Committee or any firm or corporation in which any of them are interested as officers or otherwise...
-Sec. 3837. Compromise Of Disputed Claim Arising On Contract
This contract entered into at ---------, on the -------- day of ---------, 19-, by and between A. B., of the City of---------, State of---------, party of the first part, and C. D., of the City of----...
-Sec. 3838. Compromise Of Claim For Unliquidated Damages In Tort
Know all men by these presents: That I, A. B., of---------, in consideration of the sum of --------- dollars ($--------), received to my full satisfaction of the C. D. Street Railway Company, do for m...
-Sec. 3839. Compromise And Mutual Release Of All Claims And Demands
This contract, entered into at---------,---------, this---------day of---------, 19-, by and between A. B. and C. D., Witnesses: That, whereas, various business transactions and dealings have taken p...
-Sec. 3840. Contract To Subscribe For Stock In Corporation To Be
We, the. undersigned, in consideration of the mutual promises of one another hereinafter contained, do severally subscribe for and agree to take and pay for the number of shares of the capital stock o...
-Sec. 3840-1. Contract To Subscribe For Stock In Co-Operative Really
[The contract of subscription is usually preceded by a prospectus which sets forth the advantages of co-operative ownership; the plans and specifications of the building; the cost of various apartment...
-Subscription Agreement
The undersigned, having read and approved the foregoing Plan of Organization covering the construction of --------- [insert name of building], for valuable consideration received and in consideration ...
-Sec. 3841. Voting Trust Agreement - Deposit Blank
The X. Y. Trust Company, -----------------------9. ............................... Depositary for A. B., . D. and E. F., trustees for stockholders of the G. H. Company. The undersign...
-Sec. 3842. Voting Trust Agreement - Certificate Of Deposit
No. --------- ---------, ---------, 19-. The X. Y. Trust Company of --------- hereby certifies that it has received from L. M. certificate number --------- for --------- shares of --------- dollars e...
-Sec. 3843. Voting Trust Agreement - Terms And Conditions Of Deposit
1. This deposit is made for the purpose of enabling widely separated stockholders of said the A. B. Company actively and effectively to participate in the control and management of its affairs for the...
-Sec. 3844. Contract For Pooling Stock
Know all men by these presents: That the undersigned, the owners of the number of shares of the capital stock of the A. 8. Company, a corporation organized and existing under the laws of ---------, se...
-Sec. 3845. Consolidation Agreement
This contract entered into this ---------day of------, 19-, by and between the A. B. Company, a corporation duly incorporated under the laws of the State of---------, and the C. D. Company, a corpora...
-Sec. 3846. Proxy For Voting Corporate Stock
Know all men by these presents: That I,---------, do hereby constitute and appoint --------- my attorney and substitute, for me and in my name, place and stead, to vote as my proxy at any annual or sp...
-Sec. 3847. Contract For Sale Of Shares Of Stock Of Corporation
This contract entered into at ---------, ---------, this --------- day of --, 19-, by and between A. B., party of the first part, and C. D., party of the second part, Witnesses: That said party of t...
-Sec. 3848. Contract To Make A Will!
This contract entered into this --------- day of ---------, by and between A. B., of the City of--------, State of---------, party of the first part, and C. D., of the City of ---------, State of ---...
-Sec. 3849. Contract For Mutual Conveyances Of Decedent's Estate By
This contract entered into this---------day of---------', 19-, by and between A. 'B., of the City of---------, State of---------, party of the first part, and C. D., of the City of ---------, State o...
-Sec. 3850. Contract For Easement - Drainage, Etc
This contract entered into this --------- day of -, 19-, at , by and between A. B., of ---------, party of the first part, and C. D., of ---------, party of the second part, Witnesses: That whereas s...
-Sec. 3851. Party Wall Contract
This contract entered into at ---------, ---------, this --------- day of---------, 19-, by and between A. B., party of the first part, and C. D., party of the second part, Witnesses: That whereas, ...
-Sec. 3852. Partition Fence Contract
This contract made and entered into at ---------,........, this ---------day of ---------, 19-, by and between A. B. and C. D., Witnesses: That whereas, the parties hereto are the owners, respective...
-Sec. 3853. Contract Of Employment - General Form
This contract entered into this --------- day of ---------, A. D. 19-, between A. B., of the City of---------, State of---------, and C. D., of the City of ---------, State of---------, Witnesses: ...
-Sec. 3854. Contract Of Employment - Architect-Fee Plus Cost System - Issued By The American Institute Of Architects.1
This agreement made the --------- day of ---------, in the year Nineteen Hundred and ---------, by and between ---------, hereinafter called the Owner, and --------, hereinafter called the Architect,...
-Conditions Of Agreement Between Owner And Architect. Article 1. The Architect's Services
The Architect's professional services consist of the necessary conferences, the preparation of preliminary studies, working drawings, specifications, large-scale and full-size detail drawings; the dra...
-Sec. 3854-1. Contract Of Employment - Architect-Percentage
This agreement made the ---------, day of ---------, in the year Nineteen Hundred and ---------, by and between A. B. of the ---------, County of --------and State of ---------, hereinafter called th...
-Sec. 3854-2. Contract Of Employment - Architect Or Engineer Employed By State
Whereas, the General Assembly of the State of -------- has made an appropriation for an improvement at---------as shown by the following item: ---------, and, Whereas, the--------- [insert name of Bo...
-Sec. 3855. Contract Retaining Attorney
This contract entered into this --------- day of --------, A. D. 19-, by and between A. B., of ---------, party of the first part, and C. D., of ---------, party of the second part, Witnesses: Wherea...
-Sec. 3856. Employment - Band For Concerts
This contract made and entered into this --------- day of ---------, by and between the X. Y. Company, of ---------, a corporation, party of the first part, and A. B., party of the second part; Witne...
-Sec. 3857. Contract Of Employment - Baseball Player
X. Y. LEAGUE OF PROFESSIONAL BASEBALL CLUBS Uniform Player's Contract Parties. - The A. B. Company, a corporation duly incorporated under the laws of the State of---------, herein called the Club, a...
-Sec. 3858. Contract Of Employment Of Real Estate Broker Giving Exclusive Agency
This contract entered into this --------- day of ---------, 19-, at ---------, by and between A. B., party of the first part, and C. D., party of the second part. Witnesses: That whereas, A. B. is th...
-Sec. 3859. Contract Of Employment - Circus Artist
This contract made and entered into this---------day of---------, 19-, between the X. Y. Company, a corporation hereinafter called the Employers, of the first party, and A. B., hereinafter called the ...
-Contract Of Employment - Circus Artist. Continued
12. The amount of baggage, wardrobe, apparatus and other paraphernalia carried by the Artist shall be limited to such amount, weight, size, etc., as shall be first approved by the Employers. The foll...
-Sec. 3860. Contract Of Employment Of Clerk, Etc
This contract entered into at ---------, this --------- day of ---------, 19-, by and between A. B., of---------, party of the first part, and C. D., of---------, party of the second part, Witnesses: ...
-Sec. 3861. Contract For The Employment Of Sales Agent - Exclusive
This contract entered into at---------,---------, this---------day of---------, 19-, by and between the A. B. Company, a corporation organized under the laws of ---------, and engaged in the manufactu...
-Sec. 3862. Contract For Sale On Consignment
This contract entered into at------------ , by and between the X. Y. Company, of --------, a corporation duly organized under the laws of --------, party of the first part, and C. D., of--------, part...
-Sec. 3863. Contract Of Employment - Theatrical Contract
The X. Y. Company (Incorporated Under the Laws of the State of---------) This agreement made this --------- day of ---------, 19-, between --------- Company, a corporation duly authorized and exist...
-Witnesseth
I. The party of the first part hereby engages the party of the second part as act---------for the season of the play---------, to commence on or about the--------day of---------, 19-, at a salary of $...
-Sec. 3864. Guaranty Of Payment, Endorsed On Instrument
For value received 1 hereby guarantee payment of the within --------- [insert nature of instrument as bill of exchange, promissory note, etc.]. A. B. For the necessity of written evidence, see Sec. 1...
-Sec. 3865. Guaranty Of Performance Of Contract, Endorsed On Contract
In consideration of the execution and delivery of the foregoing (or, within) contract by the above (or, within) named C. D. [name of party to whom guaranty is given], and in further consideration of o...
-Sec. 3866. Guaranty Of Existing Debt, In Consideration Of Extension
---------, ---------, 19-. To--------- (creditor): In consideration that you extend the time of payment of the debt of $--------, owing to you by X. Y., for -------- [insert obligation or obligation...
-Sec. 3867. Limited Guaranty
---------, ---------, 19-- To C. D.: I hereby guarantee the payment by X. Y. of --------- [insert obligation or obligations for which guaranty is given] ---------, at any time before---------, 19-, ...
-Sec. 3868. Continuing Guaranty With Provision For Notice Of Default
---------, ---------, 19-. To C. D.: I hereby guarantee the payment by X. Y. of --------- [insert obligation or obligations for which guaranty is given] ---------, not exceeding an indebtedness of -...
-Sec. 3869. General Letter Of Guaranty
---------, ---------, 19-. To whom it may concern: I hereby guarantee to any person who may -------- [insert obligation or obligations for which guaranty is given] ---------, not exceeding ---------...
-Sec. 3870. Standard Life Insurance Policy - "Ordinary" Or "Limited
Age ---------. Premiums $---------. The X. Y. Insurance Company Of In consideration of ---------dollars, receipt of which is hereby acknowledged, and of the payment of --------- [insert amounts and...
-Standard Life Insurance Policy: Ordinary/Limited. Continued
No condition other than as herein provided shall be exacted as a prerequisite to any such advance. Assignment. - No assignment of this policy shall be binding upon the company until it be filed with ...
-Sec. 3871. Standard Life Insurance - Endowment
THE X. Y. INSURANCE COMPANY OF--------- Amount $---------. Age ---------. Premium $---------. THE X. Y. INSURANCE CO. OF--------- In consideration of --------- dollars, receipt of which is hereby a...
-Standard Life Insurance - Endowment. Continued
No condition other than as herein provided shall be exacted as a prerequisite to any such advance. Assignment. - No assignment of this policy shall be binding upon the company until it he filed with ...
-Sec. 3872. Standard Life Insurance Policy - Endowment - Fixed Survivorship Annuity
Age ---------. Amount $--------. Premium $--------. THE X. Y. COMPANY OF --------- [name of State] In consideration of --------- dollars, receipt of which is hereby acknowledged, and of the payment...
-Standard Life Insurance Policy - Endowment - Fixed Survivorship Annuity. Continued
4. Left to accumulate to the credit of the policy with interest at --------- [here insert a rate not exceeding that used by the company in calculating its reserves] per centum per annum and payable a...
-Sec. 3873. Standard Life Insurance Policy - "Ordinary" Or "Limited
Amount $--------. Age ---------. Premiums $---------. THE X. Y. INSURANCE COMPANY OF --------- [name of State] In consideration of -------- dollars, receipt of which is hereby acknowledged, and of ...
-Standard Life Insurance Policy - "Ordinary" Or "Limited. Continued
Loans. - After three full years' premiums have been paid, the company at any time, while this policy is in force, will advance, on the proper assignment of this policy and on the sole security thereof...
-Sec. 3874. Standard Life Insurance Policy - Term
Amount $---------. Age ---------. Premium $---------. THE X. Y. INSURANCE COMPANY OF --------- [name of State] In consideration of --------- dollars, receipt of which is hereby acknowledged, and of ...
-Sec. 3875. Standard Life Insurance Policy - Term, With Right To Renew
Amount $---------. Age ---------. Premium $--------. THE X. Y. INSURANCE COMPANY OF --------- [name of State] In consideration of --------- dollars, receipt of which is hereby acknowledged, and of t...
-Sec. 3876. Life Insurance
No.--------- Age --------- The X. Y. Insurance Company, in consideration of the payment of ---------dollars, the receipt whereof is hereby acknowledged, and of the --------- [insert period for paymen...
-Provisions
Policy and Application - Entire Contract. 1. This Policy and the application herefor (a copy of which is attached hereto) constitute the entire contract between the parties. All statements made by the...
-Provisions. Continued
Cash Surrender. l0f. Upon receipt of this Policy and a full and valid surrender of all claims hereunder, without the consent or participation of any beneficiary not irrevocably designated, the Company...
-Limited Installment Table
Number of Instalments............... 25 20 19 18 17 16 15+ 14 13 12 Amount of each......................... $55.75 $68.25 ...
-Continuous Installment Table
Age of Beneficiary Number OF INSTALMENTS STIPULATES 10 15 20 25 10 and under $42.06 $41.24 $40.38 $38.48 11 42.27...
-Sec. 3877. Life Insurance - Waiver Of Premiums, Etc
THE X. Y. INSURANCE COMPANY Agreement Supplementary to Policy No. -------- Life of A. B., Insured (Waiver of premiums in event of total disability before attaining 60 years of age) In consideratio...
-Sec. 3878. Fire Insurance - Standard Form
No. ---------. X. Y. COMPANY OF --------- Amount $---------. Rate ---------. Premium $------- In consideration of the stipulations herein named and of --------- dollars premium does insure A. B. fo...
-Fire Insurance - Standard Form. Part 2
Attached to and made a part of Policy No. --------- of the X. Y. Insurance Company of ---------. ---------, Agents. This Policy is made and accepted subject to the foregoing stipulations and conditi...
-Fire Insurance - Standard Form. Part 3
This company shall not be liable for loss to accounts, bills, currency, deeds, evidences of debt, money, notes, or securities; nor, unless liability is specifically assumed hereon, for loss to awnings...
-Sec. 3879. Insurance Of Automobile - Fire, Theft And Transportation
No.-------- The X Y Company Of In consideration of the warranties and the premium hereinafter mentioned does insure the assured named and described herein upon the body, machinery and equipment of t...
-Perils Insured Against (Except As Hereinafter Provided)
(A) Fire arising from any cause whatsoever and Lightning. (B) While being transported in any conveyance by land or water - stranding, sinking, collision, burning or derailment of such conveyance, inc...
-Sec. 3880. Indemnity Insurance - Automobile Accidents, Etc
Automobile Policy . Number --------- The X. Y. Company Of (Hereinafter called the Company) In consideration of the premium and the representations of the Assured hereinafter set forth and made a pa...
-Indemnity Insurance - Automobile Accidents, Etc. Continued
The Company's liability under this indorsement for loss on account of any one accident is limited to One Thousand Dollars ($1,000.00). The company, will, however, in addition thereto, at its own expe...
-Sec. 3881. Workmen's Compensation Policy
THE X Y COMPANY OF --------- Does hereby agree with this employer, named and described as such in the declarations forming a part hereof, as respects personal injuries sustained by employes, includin...
-Workmen's Compensation Policy. Part 2
B. This Policy may be canceled at any time by either of the parties upon written notice to the other party stating when, not less than ten days thereafter, cancelation shall be effective. The effectiv...
-Workmen's Compensation Policy. Part 3
K. The Company shall be subrogated in case of any payment under this Policy, to the extent of such payment, to all rights of recovery therefor vested by law either in this Employer or, in any employe ...
-Sec. 3882. Burglary Policy
The X. Y. Company of ---------, herein called the company, in consideration of --------- dollars premium, and of the statements contained in the Schedule attached hereto and hereby made a part hereof,...
-General Agreements
1. The Assured upon the discovery of any loss covered under this Policy or any attempt to effect such loss shall, at the expense of the Company, give immediate notice thereof by telegraph to the Compa...
-Sec. 3883. Lease Of Realty
This lease witnesses, that A. B. hereby leases to C. D. the premises situate in the ------'- of ---------, in the County of --------- and State of---------, described as follows --------- [insert desc...
-Sec. 3884. Lease Of Realty
This lease witnesses that A. B., Lessor -, in consideration of the rents and covenants hereinafter stipulated to be paid and performed by C. D., the lessee-and his assigns, does hereby grant, demise a...
-Sec. 3885. Lease With Option To Purchase, Renewable Forever
This lease, made this --------- day of ---------, A. D 19-, between A. B., lessor -, and C. D., lessee-, Witnesses, that said lessor -, for and in consideration of the rents herein reserved, and cove...
-Sec. 3886. Lease - Renewal Clause
Failure of lessee to give lessor written notice ninety days in advance of the expiration of this lease, of a desire to cancel or renew same, shall be considered as evidence that said lessee desires to...
-Sec. 3887. Oil And Gas Lease
This agreement made by and between A. B., of --------- County, State of --------, of the first part, and C. D., of ---------County, State of ---------, of the second part, Witnesseth, that for and i...
-Sec. 3888. Oil And Gas Lease
Made and entered into this --------- day of------------, by and between A. B., of the ---------, County of ---------, State of ---------, party of the first part, and C. D., of the ---------, County ...
-Sec. 3888-1. Oil, Gas And Mineral Mining Lease
Agreement made and entered into --------- by and between A. B., of the --------- County of --------- and State of ---------, Trustee, of ---------, hereinafter called lessor (whether one or more), an...
-Sec. 3889. Contract For Lease Of Chattel With The Right To Purchase
This contract made this ---------day of ---------, 19-, between A. B., of ---------, of the first part, and C. D., of ---------, of the second part: Witnesses, that the party of the first part, in co...
-Sec. 3890. Literary Property - Contract Between Publisher And
This contract entered into this ------ day of ---------, 19-, by and between A. B., of ---------, party of the first part, and The C. D. Company, a corporation duly organized under the laws of ------...
-Sec. 3891. Contract Between Publisher And Author For Publication
This contract entered into at --, this ---- day of ------ , 19-, by and between A. B., of ---------, party of the first part, and C. D., party of the second part, Witnesses: That, whereas, said party...
-Sec. 3892. Contract For The Manufacture Of Goods
This contract entered into at ---------, this --------- day of ---------, 19-, by and between A. B., of ---------, party of the first part, and C. D., of ---------, party of the second part, Witnesses...
-Sec. 3803. Marriage - Ante-Nuptial Agreement With Provision For Release Of Dower
This contract entered into this --------- day of ---------, ID-, by and between A. B. and C. D.. both of ---------,---------, Witnesses: That whereas, the parties hereto contemplate a marriage with ...
-Sec. 3894. Contract For Separation - Release Of Dower, Etc
This contract of separation entered into at ---------, -------, this ---------day of ---------, 19-, by and between A. B. and C. B., husband and wife, Witnesses: That whereas, the parties hereto have...
-Sec. 3895. Mortgage Of Realty
Know all men by these presents: That A. B., of the --------- of ----------., County of --------- and State of ---------, in consideration of the sum of --------dollars, to him paid by C. D., of the -...
-Sec. 3896. Mortgage Of Personalty
Be it known, that A. B., mortgagor -, in consideration of --------- to him paid by C. D., mortgagee -, the receipt of which is hereby acknowledged, does hereby Bargain, Sell and Convey to the said C. ...
-Sec. 3897. Mortgage Of Personalty
Know all men by these presents: That A. B., of the --------- County of --------- and State of ---------, in consideration of --------- [insert consideration] to him paid by C. D., of the ---------Cou...
-Sec. 3898. Motion Picture - License Contract
Application and Date,---------. L cense No. ---------. (Original - for Home Office) Population, ---------. Account No.---------. THE X Y COMPANY Admission Price, $ Seating Capacity,--------. Short...
-Motion Picture - License Contract. Continued
4. In the event the films named herein or any part thereof are destroyed or damaged in any way while in the possession of the exhibitor, the exhibitor shall furnish the X.Y. Company a sworn affidavit ...
-Sec. 3899. Motion Pictures - Contract Between Producer And Theatre. Sharing Contract
This agreement, made and entered into by and between A. B., of ---------, of the first part, and the X. Y. Company, of the second part, in consideration of one dollar, by each to the other in hand pai...
-Sec. 3900. Negotiable Instrument - Promissory Note
$---------. ---------, ---------, 19-. --------- after date, for value received, --------- promise to pay to --------- or order, ---------dollars, with interest from date, until paid, at ---------per...
-Sec. 3901. Negotiable Instrument - Cognovit Note
$--------. -------,--------, 19-. --------- after date, for value received, --------- promise to pay to --------- or order,---------dollars, with interest from date, until paid, at ---------per cent....
-Sec. 3902. Negotiable Instrument - Promissory Note With Collateral
clause. $-------. -------.-------, 19-. --------- days after date, ---------promise to pay to the order of the --------- Bank, --------- dollars, for value received, at the office of said Bank with ...
-Sec. 3903. Negotiable Instrument - Note With Interest Coupons Secured By Mortgage
$---------. ---------,---------, 19-. ---------after date, for value received,---------promise to pay to the order of ---------,--------- dollars, with interest from date, payable --------- at the r...
-Sec. 3904. Negotiable Instrument - Bill Of Exchange
$---------. ---------, ---------, 19-. On demand (or at sight, or at ---------days sight, or ---------days after date) pay to the order of E. F. --------- dollars and charge the same to the account o...
-Sec. 3905. Negotiable Instrument - Certificate Of Deposit
$---------. The --------- Bank ---------, ---------, 19-. This certifies that ---------has deposited in this bank --------- dollars, payable with interest at the rate of --------- per cent. per annum...
-Sec. 3906. Protest
(Copy of bill or note protested) United States of America, State of ---------, -------- County. ss: Be it known by this Instrument of Protest: That at the close of banking hours, on ---------the ...
-Sec. 3907. Notice Of Protest
$---------. ---------, ---------, 19-. Take notice, that a ---------, dated -------, 19-, for --------- dollars, drawn by --------- on ---------, payable --------- to the order of --------- at ------...
-Sec. 3908. Promissory Note Executed By Guardian, Receiver, Trustee
$---------. ---------,---------, 19-. ---------after date, in my capacity as --------- [insert designation as trustee and the like so as to identify the trust fund] and not inmy personal capacity, I...
-Sec. 3909. New Contract Modifying Original Contract
This contract entered into this --------- day of ---------, A. D. 19-, by and between A. B., of the City of ---------, State of ---------, party of the first part, and C. D., of the City of ---------,...
-Sec. 3910. Option For Purchase Of Realty
This contract entered into this ---------day of ---------, 19-, at ---------,--------, between A. B., of ---------(hereinafter designated as first party), and C. D., of ---------, --------- (hereinaf...
-Sec. 3911. Option Contract To Re-Purchase, If Vendee Desires To Re-Sell
Whereas, A. B. has this day purchased --------- [insert description of property], for the price of ---------; And whereas, by the mutual agreement of said parties, said price was paid not only for sa...
-Sec. 3912. Option To Purchase Stock In Corporation
In consideration of --------- dollars ($---------), the receipt of which is hereby acknowledged, I hereby give to C. D. the right and option to purchase from me at any time within ---------days from t...
-Sec. 3913. Sale Of Personalty - Bill Of Sale
Know all men by these presents: That A. B., of the City of ---------, County of --------- and State of ---------, in consideration of --------- [insert the consideration], to him paid by C. D., of th...
-Sec. 3914. Sale Of Personalty - Contract For Delivery In Instalments
The A. B. Company, of the City of ---------, State of ---------, vendor, agrees to sell and deliver to the C. D. Company, of the City of ---------, State of ---------, purchaser, and the said purchase...
-Sec. 3915. Sale Of Personalty - Conditional Sale On Credit, Reserving
This agreement, made at ---------, in --------- County, Ohio, between --------, the first party hereto, and ---------, the second party hereto. Witnesseth, that whereas the said 6econd party ha - thi...
-Sec. 3916. Car Trust Agreement
Memorandum of agreement made this --------- day of ---------, A. D. -------, between A. B., trustee, and the X. Y. Company, whereby said A. B. agrees to lease to the said X. Y. Company, and the said X...
-Sec. 3917. Sale Of Personalty- Motor Vehicle - Retail
Name--------- Frame No. --------- Motor No. --------- THE X Y MOTOR CO. Retail Car Contract Starter No. --------- Del'y Order No. --------- Date Delivered --------- ---------, ---------, 19- P...
-Guarantee
In order to avoid misunderstanding, we desire our patrons to clearly understand that our guarantee for one year from date of delivery of the car to you is in respect to defective material only. We wi...
-Sec. 3918. Sale Of Personalty - Motor Vehicle - New
Know all men by these presents: That A. B. of --------- County of ---------, State of ---------, the Grantor -, for the consideration of ---------dollars ($---------), paid by C. D., of ---------Coun...
-Sec. 3919. Sale Of Personalty - Motor Vehicle - Used
Know all men by these presents: That A. B., of the --------- County of ---------, State of ---------, the Grantor -, for the consideration of --------- dollars ($---------), paid by C. D., of the --...
-Sec. 3920. Contract For Sale Of Stock In Trade, Fixtures and Lease
This contract entered into at ---------, ---------, by and between A. B., of ---------, ---------, party of the first part, and C. I)., of ---------, ---------, party of the second part, Witnesses: ...
-Sec. 3921. Contract For Sale Of The Practice Of A Physician
This contract entered into at ---------, ---------, this --------- day of ---------, 19-, by and between A. B., of ---------, party of the first part, and C. D., party of the second part, Witnesses: ...
-Sec. 3923. Storage Contract
---------, ---------, 19-Received from A. B. for storage subject to the terms and conditions herein mentioned, the property hereinafter described, to be delivered to C. D. or his assigns upon the paym...
-Sec. 3924. Contract Of Subscription - General Form
We, the undersigned, in consideration of the mutual promises of one another, do hereby respectively agree to pay the sums of money set opposite our respective names for --------- [insert object for wh...
-Sec. 3925. Subscription Agreement For Endowment Of A Church
In consideration of the efforts of the trustees of the --------- church, of the City of ---------, Ohio, to raise an endowment fund of -------- dollars, and of the agreement of said trustees to recei...
-Sec. 3926. Contract For Support
This contract entered into this --------- day of ---------, A. D. 19-, by and between A. B., of the City of ---------, State of ---------, party of the first part, and C. D., of the City of ---------,...
-Sec. 3927. Telegram
X. Y. TELEGRAM Form-------- CLASS OF SERVICE DESIRED Telegram Day Letter Night Message Night Letter Receiver's No. Check ...
-All Messages Taken By This Company Are Subject To The Following Terms
To guard against mistakes or delays, the sender of a message should order it repeated, that Is, telegraphed back to the originating office for comparison. For this, one-half the unrepeated message rat...
-Classes Of Service
Telegrams. - A full-rate expedited service. Night Messages. - Accepted up to 2.00 A. M. at reduced rates to be sent during the night and delivered not earlier than the morning of the ensuing business...
-Sec. 3928. Contract For Telephone Service
The Subscriber requests the X. Y. Telephone Company (hereinafter styled the Company) to install and maintain at--------- a telephone on copper metallic circuit --------- [with not exceeding --------- ...
-Sec. 3929. Theatrical Contract - Author And Producer
Agreement made and entered into the --------- day of ---------, 19-, by and between A. B., of ---------, State of ---------, through his authorized agents, the E. F. Agency, hereinafter known as the ...
-Theatrical Contract - Author And Producer. Continued
Eighth. - The party of the second part agrees to give prominence to the name of A. B. as sole author of the said play upon programmes, announcements and all other advertising and printing matter used ...
-Sec. 3930. Theatrical Contract - Assignment Of Interest
This agreement made this ---------day of ---------, 19-, by and between A. B., of the --------, and State of ---------, and the X. Y. Corporation, a corporation duly organized and existing under and b...
-Sec. 3931. Theatrical Contract - Producer And Theatre Owner. Theatre Contract
Memorandum of agreement, entered into this --------- day of ---------, 19-, between A. B., party of the first part and C. D., party of the second part. Whereby it is mutually agreed that said party o...
-Sec. 3932. United States - Contract For Manufacturing At Cost, Plus
Contract No.--------- Proposal No.--------- Order No. --------- Req. No.--------- ...
-Signal Corps United States Army Contract For Aeronautical Equipment
These Articles of Agreement, entered into this --------- day of ---------, 19-, by and between the X. Y. Company, a corporation organized and existing under the laws of the State of ---------, party o...
-Article I. Articles Contracted For
The Contractor shall make for the Government the following articles hereinafter called the articles, namely: Five hundred (500) U. S. A. standardized 12-cylinder aircraft engines, in accordance with...
-Article II. General Provisions
Time being of the essence of this contract, the Contractor agrees to provide with' the Utmost dispatch, at the best prices obtainable: (1) Such administrative, purchasing, manufacturing and accountin...
-Article III. Deliveries
The Contractor agrees to deliver the articles according to the following schedule: --------- [insert times and quantities]. In view of the present uncertain factors inherent in the articles, and in t...
-Article IV. Price
The price to be paid to the Contractor for the articles herein contracted for shall be the sum of the following items: (1) The actual cost of production as in Article V hereof defined and in Article ...
-Article V. Definition Of Actual Cost
The actual cost of production of the articles hereby contracted for, hereinafter sometimes called Actual Cost, shall be determined as set forth in Article VII, and is hereby defined as consisting of...
-Article VI. Payments
The Government will pay the following items within ten days of their determination, unless otherwise herein provided, as follows: (1) For all direct materials, supplies and equipment accessories, pur...
-Article VII. Determination Of Costs And Payments
The determination of the Actual Cost as in Article V hereof defined, and of all questions arising under Article VI, shall be promptly made by or under the direction of the Accounting Officer, in accor...
-Article VIII. Accounting Provisions
The Accounting Officer, or his designee, shall have the right to provide, should he deem such action or actions necessary, a detailed classification of accounts with the definitions to be used in conn...
-Article IX. Inspection
The Government shall have inspectors at each of the Contractor's factories and at other points at its discretion where and during the time the articles hereby contracted for and their component parts ...
-Article X. Changes In Specifications
No changes shall be made in the drawings or specifications attached hereto and made a part of this contract, except as provided in this Article. Changes may be made at any time by mutual agreement be...
-Article XI. Termination Before Completion
In the event of the failure of the Contractor to substantially comply with the terms of this contract, or in the event that in the opinion of the Chief Signal Officer of the United States Army the pub...
-Article XII. Special Test Of Articles
Without prejudice to the right of the Government to cancel this contract for any other reason, it is agreed that, in view of the fact that the articles to be furnished under this contract, and the des...
-Article XIII. Disposition Of Property On Termination Or Completion
Upon the completion of this contract, whether by the Contractor or the Government, or the termination of the contract without further performance thereof, or from time to time during the performance o...
-Article XIV. Covenant Against Encumbrances
The Contractor agrees not to create or suffer to be created any mortgage, lien, pledge or other encumbrance upon any of the increased facilities, materials, supplies or other property for which the Go...
-Article XV. Contract Not Assignable By Contractor
Neither this contract nor any interest therein shall be transferred or assigned by the Contractor to any person, firm or corporation. ...
-Article XVI. Officials Not To Benefit
No member of or delegate to Congress, or resident commissioner, is or shall be admitted to any share or part of this contract, or to any benefit that may arise therefrom. But this article shall not ap...
-Article XVII. No Prison Labor
No person or persons shall be employed in the performance of this contract who are undergoing sentence or imprisonment at hard labor, which has been imposed by the courts of the several States, Territ...
-Article XVIII. Settlement Of Disputes
Except as this contract shall otherwise provide, any doubts or disputes which may arise under this contract, shall be referred to a Board composed as provided in Article VII hereof for determination. ...
-Article XIX. Notice
Notice under this contract shall be deemed to have been sufficiently given to and received by the Contractor when mailed in a sealed, post-paid wrapper and addressed to the Contractor. Whenever notice...
-Article XX. Exploitation Forbidden
The Contractor agrees to refrain from exploiting, by publicity or otherwise, its product manufactured in pursuance of this contract, or in any way publicly advertising the fact of the manufacture of s...
-Article XXI. Contracting Officer
Whenever the term Contracting Officer is used in this contract, the same shall be construed to mean the Contracting Officer executing this contract, his successor or successors, his duly authorized ...
-Schedule A
Memorandum on Definition of Actual Costs and on Method of Collating Cost Data - Definitions. Definition of Actual Cost. - The actual cost of production of the articles hereby contracted for is hereb...
-Schedule A. Continued
(3) Payments according to a definite pension plan to disabled and veteran employes or their families, and not included in liability insurance or other items mentioned herein. (4) Net results of opera...









TOP
previous page: The Law Of Contracts Vol5| by William Herbert Page
  
page up: Business Law Books
  
next page: A Treatise On The Construction Of The Statute Of Frauds | by Causten Browne